Terms of Service

Last updated: December 2024

Agreement to Terms

By accessing or using the Moda Outdoor Living website and services, you agree to be bound by these Terms of Service. If you do not agree to these terms, please do not use our services.

Services Description

Moda Outdoor Living provides outdoor construction and design-build services including but not limited to:

Pool construction and remodeling
Hardscape installation (pavers, driveways, patios)
Landscape design and installation
Outdoor kitchen construction
Pergola and patio cover installation

Consultations and Quotes

Free consultations are provided to assess project scope and provide estimates. Quotes are valid for 30 days unless otherwise specified. Final pricing may vary based on site conditions, material availability, and project modifications.

Project Agreements

All construction projects require a signed contract specifying scope of work, timeline, payment terms, and other project details. The website does not constitute a binding agreement for services.

SMS Communications

By providing your mobile phone number and opting in through our website, scheduling tools, or other communication methods, you consent to receive SMS (text message) communications from Moda Outdoor Living.

SMS use cases may include:

Appointment confirmations and reminders
Project updates and scheduling notifications
Customer service communications
Promotional or marketing messages (when applicable)

Message frequency may vary.

SMS Opt-Out Instructions

You may opt out of receiving SMS messages at any time by replying STOP to any text message. After opting out, you will no longer receive SMS communications from us unless you re-enroll.

For assistance, reply HELP or contact us directly at office@modaoutdoorliving.com or (747) 463-3326.

Message & Data Rates

Message and data rates may apply depending on your mobile carrier and plan. Moda Outdoor Living is not responsible for any charges incurred from SMS messages.

Carrier Disclaimer

Mobile carriers are not liable for delayed or undelivered messages.

Age Restriction

Our services, including SMS communications, are intended for individuals 18 years of age or older. By using our website or opting into SMS communications, you confirm that you are at least 18 years old.

User Responsibilities

When using our website and services, you agree to:

Provide accurate and complete information
Not use the website for any unlawful purpose
Not attempt to interfere with website functionality
Respect our intellectual property rights

Intellectual Property

All content on this website, including text, images, logos, and designs, is the property of Moda Outdoor Living and is protected by copyright and trademark laws. You may not reproduce, distribute, or use our content without written permission.

Limitation of Liability

Moda Outdoor Living is not liable for any indirect, incidental, special, or consequential damages arising from your use of our website. Our liability is limited to the maximum extent permitted by law.

Warranty and Guarantees

Specific warranty terms for construction projects are detailed in individual project contracts. Website content is provided "as is" without warranties of any kind.

Governing Law

These Terms of Service are governed by the laws of the State of California. Any disputes shall be resolved in the courts of Los Angeles County, California.

Licensing

Moda Outdoor Living operates under California Contractor License #1102152 (Classifications: B, C-27, C-53). License verification is available through the California Contractors State License Board (CSLB).

Changes to Terms

We reserve the right to modify these Terms of Service at any time. Changes will be effective immediately upon posting. Continued use of our services constitutes acceptance of modified terms.

Contact Information

For questions about these Terms of Service, please contact us:

Email: office@modaoutdoorliving.com
Phone: (747) 463-3326
Address: 21243 Ventura Blvd #104, Woodland Hills, CA 91364